Welcome to GC Contractor Services. By accessing and using our website or engaging in our services, you agree to comply with and be bound by the following Terms and Conditions. If you do not agree with any of these terms, please do not use our website or services.

Services Provided

GC Contractor Services offers a wide range of services, including but not limited to:

• Construction Services – New construction of residential and commercial properties.
• Restoration Services – Concrete restoration, waterproofing, and general repairs.
• Remodeling Services – Kitchen, bathroom, and full property renovations.
• Painting Services – Professional interior and exterior painting services.

All project details, timelines, and pricing will be clearly outlined in your contract before the start of any work. The services provided may vary depending on the project and the client’s specific needs.

Payment Terms

• Deposit: A deposit is required before the commencement of any project. The deposit amount will be specified in the contract and is typically a percentage of the total project cost.
• Final Payment: The remaining balance is due upon completion of the project, or according to the payment schedule outlined in the contract.
• Late Payments: If payments are not received on time, additional charges or late fees may apply. Work on the project may also be delayed until the outstanding balance is paid.
  GC Contractor Services reserves the right to suspend or terminate work if payments are not made in accordance with the agreed terms.

Cancellations and Refunds

• Cancellations: Should you need to cancel a project, cancellations must be made in writing. If work has already begun, the client may be responsible for any completed work, including materials purchased for the project.
• Refunds: Refunds for services will be evaluated on a case-by-case basis depending on the stage of the project. Refund eligibility may be limited once work or purchases (such as materials) have been made.
  Any request for a refund must be made in writing and will be processed in accordance with the terms specified in the project contract.

Liability

GC Contractor Services is not liable for delays or failures in performance due to factors beyond our control, including but not limited to:

• Weather conditions
• Natural disasters
• Supply chain disruptions
• Labor shortages

While we strive to meet the deadlines and expectations set in the project agreement, external factors may occasionally cause delays that are outside of our control.

Warranty

GC Contractor Services provides a limited warranty for all services rendered, which covers specific issues related to workmanship. The warranty terms will be specified in the project agreement and typically range from 6 months to 5 years, depending on the service provided.
The warranty does not cover damage resulting from external factors, misuse, or improper maintenance by the client.

Intellectual Property

All content on this website, including text, images, graphics, logos, and any other materials, are the intellectual property of GC Contractor Services or its licensors. You may not use, copy, reproduce, distribute, or modify any of the content without the express written consent of GC Contractor Services.

Site Usage

You agree to use the website only for lawful purposes and in accordance with these Terms and Conditions. You are prohibited from using the site in a way that could disable, damage, or impair the website or interfere with any other user’s ability to access or use the website.

Privacy Policy

GC Contractor Services respects your privacy. Please refer to our Privacy Policy to learn how we collect, use, and protect your personal information when you interact with our website or services.

Third-Party Links

Our website may contain links to third-party websites. These links are provided for your convenience. GC Contractor Services does not control or endorse the content of third-party websites and is not responsible for their availability or accuracy.

Governing Law

These Terms and Conditions are governed by and construed in accordance with the laws of the State of Florida. Any disputes arising from these terms will be resolved in the courts of Florida.

Dispute Resolution

In the event of a dispute, both parties agree to first attempt to resolve the matter through good-faith negotiation. If resolution cannot be reached through negotiation, the dispute will be resolved through binding arbitration in Florida.

Termination of Access

GC Contractor Services reserves the right to suspend or terminate your access to the website and services if you violate these Terms and Conditions or engage in any conduct that could harm our business or reputation.

Changes to Terms

GC Contractor Services reserves the right to modify or revise these Terms and Conditions at any time. Any changes will be effective immediately upon posting on the website, and your continued use of the website and services will constitute your acceptance of those changes.

Contact Us

If you have any questions or concerns about these Terms and Conditions or any of our services, please contact us at:
GC Contractor Services
Contact Information - 

Phone - 386-257-6199

Email -[email protected]